Terms and Conditions

Welcome to Pixelwand!

These Terms and Conditions ("Agreement") govern your use of our services and website. By engaging Pixelwand for software development services, you ("Client") agree to be bound by these terms. If you do not agree to any part of the Agreement, please refrain from using our services.

1. Services Offered

Pixelwand provides custom software development, UI/UX design, SaaS product engineering, AI integration, and cloud infrastructure services. Scope of work for each project will be defined in a separate Statement of Work (SoW).

2. Payment Terms

Project fees are determined based on the scope. Unless otherwise stated, a 50% upfront payment is required to begin work. Remaining amounts are tied to milestone completions or monthly retainers. Late payments may result in service delays or penalties.

3. Intellectual Property

All intellectual property developed specifically for the Client will be transferred upon final payment. Pixelwand reserves the right to reuse non-client-specific tools, frameworks, or methodologies.

4. Confidentiality

Pixelwand and the Client agree to maintain the confidentiality of all proprietary or sensitive information exchanged throughout the engagement. This obligation continues post-termination.

5. Timelines & Responsibilities

While we strive to meet all timelines, delivery dates may shift due to client-side delays, changes in scope, or technical dependencies. The Client agrees to provide timely access, decisions, and assets required for development.

6. Revisions & Scope Changes

Revisions within the original scope are accommodated. Any additional requirements may incur extra charges and updated timelines. Scope changes must be agreed to in writing.

7. Warranties & Bug Fixes

Pixelwand offers a 30-day bug-fix warranty after project delivery. Bugs caused by third-party systems, improper usage, or changes to requirements post-launch are not covered under warranty.

8. Termination

Either party may terminate this agreement with 7 days’ written notice. Work completed up to the termination date will be invoiced accordingly. Upon termination, Pixelwand will deliver all applicable assets to the Client.

9. Limitation of Liability

Pixelwand is not liable for indirect, incidental, or consequential damages including, but not limited to, data loss, missed business opportunities, or third-party service failures.

10. Use of Portfolio

Pixelwand may display non-confidential elements of a project in our portfolio or marketing channels. If you prefer to opt-out, notify us in writing.

11. Governing Law

This Agreement shall be governed by and interpreted in accordance with the laws of India. Disputes arising will be subject to the exclusive jurisdiction of the courts in that jurisdiction.

12. Contact Us

For any concerns or clarifications, please contact us at:
📧 contact@pixelwand.live
🌐 www.pixelwand.live